WRECKSTAGE 99

WRECKSTAGE 99

Overview

The latest edition of this contract is WRECKSTAGE 2010.

Download an example of this contract

Explanatory notes

Part I

Part II

 


 

Part I

Box 4 now refers to GT, NT and DWT.

There is a new Box 9 (Permits) which deals with changes made to Clause 6. The remaining boxes, up to and including the original Box 12, have been re-numbered accordingly.

Box 13 (Security Requirements) has been deleted as a result of changes made to Clause 13. 

A new paragraph has been added to the Preamble above the signature boxes, to deal with any conflict that may arise between the terms and conditions of Part I and Part II.

Part II

There are now 18 clauses in WRECKSTAGE 99, all of which featured in the original WRECKCON. Changes have been made to original WRECKCON clauses 1, 3, 4, 5, 6, 9, 12, 13, 14, 15, 17, 18 and 19.

The line numbering adopted in this article relates to the new WRECKSTAGE 99, unless otherwise stated.

Clause 1 - Definition

Lines 5 - 7 of Clause 1 of WRECKCON, which dealt with Mobilisation Costs, have been deleted as this matter is dealt with in Box 10. It should be noted that, in order to give the agreement as wide an application as possible, the term “Vessel” not only includes the ship, but also cargo, containers, stores and bunkers.

Clause 2 - The Services

This clause deals with the Contractors’ obligations in rendering the services set out in Box 7, as well as the provision of personnel, craft and equipment, the method of work, and any change in the method of work, or provision of personnel, craft and equipment. Consistent with the approach taken in the 1989 Salvage Convention, the Contractor is obliged to exercise “due care” when rendering the services. Provided that it is not inconsistent with the nature of the services to be rendered, the Contractor must also exercise “due care” to minimise damage to the environment.

Clause 3 - Company Representative

This clause provides for a representative of the Company to be available during the services, with full authority to act on behalf of the Company. It also deals with the provision of information required by the Contractor and for the attendance of sufficient officers, or equivalents, who are fully conversant with the layout of the Vessel and its cargo system. The wording of this clause has been amended to make it clear that the primary role of the ship’s officers, or equivalents, is to provide advice and not assistance to the Contractor.

Clause 4 - Change of Method of Work  and/or Personnel, Craft and Equipment

This clause deals with the circumstances under which the Contractor may seek a variation to the “lump sum” price.

Clause 5 - Miscellaneous

This clause deals with matters such as the marking of the Vessel; use of the Vessel’s machinery and equipment; removal or jettison of parts of the Vessel and/or its cargo, and provision of plans and manifests.

The original WRECKCON sub-clause 5.4 providing indemnity for the removal, disposal or jettison of property has been deleted, as it is considered that the “hold harmless” provisions of the new sub-clause 14.2.2 adequately deal with this matter.

Clause 6 - Permits

This clause deals with the need to obtain licences, approvals, authorisations and permits. In practice this clause has frequently caused problems as the Clubs have always been of the opinion that the Contractor should arrange all permits, licences, etc. necessary for his operations.

The Clubs wanted to reverse the obligation by placing the burden on the Contractor to obtain any Permits, etc. However, the final wording leaves it to the parties to decide this matter on a case by case basis by nominating, in Box 9, the party who will be responsible for obtaining permits, licences, etc.

Clause 7 - Delays

The background to this clause is that the Contractor, in calculating his lump sum price, will frequently make an allowance for time lost due to adverse weather or sea conditions, based on his experience of the area/time of year in question. What the Contractor cannot assess in advance is delays that might arise due to events or other circumstances outside his control.

The total number of days “free time”, which do not have to be consecutive, are set out in Box 16. All additional days lost due to adverse weather or sea conditions, as well as all days lost due to other reasons outside the control of the Contractor, shall be paid as additional compensation at the rate set out in Box 14. The Contractor is obliged to advise the Company promptly of all such delays and must confirm his advice in writing as soon as possible.

It is important to note that the Company does not have the right under WRECKSTAGE 99 to terminate the Agreement, even where the delays are prolonged. Consequently, it is important that the Delay Payment Rate in Box 14 is set at a level which will discourage Contractors from seeking to prolong unnecessarily the services under the Agreement.

Clause 8 - Termination

The provisions of this clause set out the circumstances under which the Agreement may be terminated by the Company (sub-clause 8.1); the manner in which the suspension or termination of the Agreement will be carried out by the Contractor (sub-clause 8.2); and the situation if permission to suspend or terminate the services is not given by the competent authorities (sub-clause 8.3).

Clause 9 - Delivery

This clause is concerned with delivery of the Vessel on completion of the services. Sub-clause 9.1 deals with delivery of the Vessel to the Company, the nature of the place of delivery, and the consequences of any delays.

In sub-clause 9.2 there is provision for delivery by the Contractor at an alternative place, if the nominated place becomes impossible or unsafe to enter, and the Company is unable to nominate another place. This clause also deals with the additional costs incurred as a consequence.

Sub-clause 9.3 provides for delivery under control of pumps, generators, compressors, etc. and payment for same. The consequences of a failure by the Company to take delivery, and the right of the Contractor to sell the property in such a situation are dealt with under sub-clause 9.4. Finally, sub-clause 9.5 explains that references to the “Vessel” includes parts of the Vessel and/or its cargo and that delivery of such may take place at different times and at different places.

Clause 10 - Price and Conditions of Payment

This clause is fundamental to the proper working of WRECKSTAGE 99 and deals with the price for the services, referred to as the “lump sum” (sub-clause 10.1); provides that instalments are fully and irrevocably earned when they become due and are non-returnable (sub-clause 10.2); provides for payment to be made to the Contractor without deduction (sub-clause 10.3); deals with the bank account for payment (sub-clause 10.4); and gives a right of termination in the event that payment is not made in accordance with the terms of the Agreement, or if security is not provided in accordance with the provisions of Clause 13 (sub-clause 10.5).

Clause 11 - Time of Payment and Interest

Clause 11 enables the Contractor to charge the Company interest at the rate stated in Box 12 in the event payment is not made in accordance with the terms of the Agreement.

Clause 12 - Extra Costs

This clause provides for any various extra costs that might be incurred as well as liability for same. Such expenses/costs are to be paid as and when they fall due by the parties as indicated in Box 13.

In sub-clause 12.6, at line 227, the words “portable salvage” have been inserted to make it clear that the equipment referred to does not include sheerlegs, cranes, tugs, barges, etc.

Clause 13 - Security

While the Security Clause of WRECKSTAGE 99 requires the Company to provide an irrevocable and unconditional security, it is not required to be in the form of a bank guarantee, but can be in any form as agreed between the parties. The Company is required to provide satisfactory security to cover monies due to the Contractor. The Contractor may also commence operations without the provision of initial security, but can request it to be provided at a later stage.

Clause 14 - Liabilities

This clause has proved particularly troublesome throughout the history of the original WRECKCON. The clause establishes the position between the parties with regard to liability for their own personnel, craft and equipment. The Clubs raised objections to the wording of the WRECKCON Liabilities Clause, in particular to the indemnities in respect of wreck removal or third party claims. The Clubs reasoned that third party claims should be covered by the common law of negligence for which a Contractor can obtain suitable insurance cover, the cost of which will form part of his lump sum price, and that the party liable to remove a subsequent wreck should meet such claims through his own P&I Club cover, or other liability insurance. The result of the discussions with the Clubs is a new and much shorter clause which deals only with loss or damage to property of the Contractor/ Company.

It should also be noted that sub-clause 14.2.1 has also been amended at lines 264 - 267 by including the words “excluding portable salvage equipment, materials or stores which are reasonably sacrificed during the disposal or other operations on the Vessel, unless the Contractor is the party responsible for such costs as indicated in Box 13 (a))”. This is to avoid any conflict or ambiguity as between sub-clause 12.6 and this sub-clause 14.2.1.

Contractors should note that the cross indemnities relating to liability for pollution from the “Vessel” or from the Contractor’s Craft are excluded from the Agreement. Contractors should therefore ensure that they have adequate and proper cover for such risks.

In addition the Clubs requested that the WRECKCON sub-clause 14.4 be deleted, as it could be used to argue that if the Contractor is liable to a third party and is unable to limit his liability, then the Company should indemnify the Contractor for any excess liability. This could result in the Company accepting liabilities in excess of its own limit of liability.

Clause 15 - Himalaya Clause

This standard clause has been slightly amended (lines 283-284) from the version currently found in WRECKCON in order to clarify the position if the Company is the demise or bareboat charterer of the Vessel.

Clause 16 - Lien

This is a standard clause which remains unchanged from WRECKCON. The clause provides that the Contractor has a possessory lien on the Vessel for any amounts due to him under the Agreement.

Clause 17 - Time for Suit

This clause deals with the period within which a claim, arising under WRECKSTAGE 99 may be brought by either party.

The wording of the clause has been slightly amended from that found in the WRECKCON Agreement in that a claim must be brought either within 12 months of completion or termination of the services, or within 12 months of notification of a claim by a third party, but any suit must be brought within one year of the notification to the party against whom the claim is made.

Clause 18 - Governing Law and Arbitration

This clause remains unchanged from the original WRECKCON other than reference is now made to the Arbitration Act 1996 and LOF 1995. Although BIMCO normally endeavours to have its Standard Law and Arbitration Clause incorporated into approved forms, the specialised nature of the WRECKSTAGE 99 Agreement makes it more sensible to provide for arbitration in London before a member of the existing Panel of Lloyd’s Arbitrators, who are experts in this field. However, Clause 18 does follow the traditional pattern of the BIMCO Law and Arbitration Clause in providing the parties with the option to agree to a different jurisdiction and place of arbitration. In addition, should the parties fail to indicate their preference for a particular alternative jurisdiction and place of arbitration then, by default, the dispute will be referred to London arbitration subject to English law.

Clause 19 - Warranty of Authority

This clause has been deleted from WRECKSTAGE 99 as it is now dealt with by the additional Part I Preamble.  


Copyright
Copyright in WRECKSTAGE 99 is held jointly by the ISU and BIMCO.

(Printed in BIMCO Bulletin No. 6, 1999)

Create or edit a contract

The one-stop digital shop for all the standard maritime contracts and clauses you’ll ever need.

 
 

Latest Related News

View All News

Stay up to date

Receive news on the latest developments related to shipping contracts and clauses. Get advice on choosing the right contract for your business and which clauses to add and why.

ELSEWHERE ON BIMCO

Holiday calendar

BIMCO's Holiday Calendar covers general holidays in over 150 countries, plus local holidays and working hours in more than 680 ports around the world.

Taxes, tariffs & charges

Access information on national, regional or port tariffs, taxes and charges.

Learn about your cargo

For general guidance and information on cargo-related queries.

More about cargo